A trade contractor on a public works new high school construction project filed suit against the firm’s construction manager client for breach of contract as an alleged third-party beneficiary and negligence seeking in excess of $3.8 million dollars for alleged contract balance and delay and disruption damages. Following nearly two years of litigation and after the court granted the firm’s summary judgment and summary adjudication motions, the District and trade contractor settled with no contribution by the firm’s client.
San Joaquin Superior Court Case No. CV033417
Counsel: P. Randolph Finch Jr. and Andrea L. Petray